Experience Matters

The project centered on the installation of a 230 kV transmission line: 24 miles underground and 3.5 miles overhead, through an extremely diverse and environmentally sensitive and challenged series of districts. The major infrastructure subcontractor alleged major delay and disruption impacts caused by the main contractor. Engaged to provide claim support services to the main contractor against the subcontractor’s claims. Prepared a defense position paper involving a CPM analysis, disruption analysis, and contract entitlement to rebut the subcontractor’s expert report, which ultimately resulted in mediation proceedings and a series of settlement negotiations. Also provided claims avoidance training and lessons learned reviews to the main contractor construction team to facilitate improved management of future similar projects.

Provided a claims prevention training seminar for a chemical company and its EPCM contractor on an $800 million methanol project

On behalf of an African country, provided a rebuttal report and testimony in international arbitration regarding a claimant’s alleged value of its lost business opportunity after performing, at its own expense and risk, engineering and project development services for a port and rail project that it was not awarded. Evaluated the class of the claimant’s estimates of the project costs before and after it performed its de-risking of the project to lower project costs and determined that the estimates were inaccurate based on the information that was available to prepare the estimates. Thus, found that the claimant’s alleged project savings and its claim amount were speculative.

Provided entitlement and damages analyses on an $11 million dispute arising from the construction of a semi-conductor fabrication facility. Prepared issue analyses related to mechanical and piping design changes and performed estimates on mechanical and piping work to analyze cost overruns.

On behalf of an owner, performed a schedule quality assurance review and schedule risk assessment of the integrated master schedule for a $14 billion oil sands project.

On behalf of a major U.S. oil company, performed an analysis and provided deposition testimony regarding a claim against a contractor for $29 million in improper charges on a reimbursable contract for the fabrication of one offshore gas compression platform and two wellhead platforms.

On behalf of an equipment supplier, developed estimates to complete four power plant projects that the contractor left incomplete.

On behalf of an owner, performed a detailed schedule quality assurance review of the engineering, procurement, construction, commissioning and start-up activities of a central processing facility (CPF). The CPF consisted of utilities, inlet separation, two oil trains, associated gas compressors, natural gas liquids and injection gas units. Identified logic problems and overuse of constraints, which made the indicated critical and near-critical paths questionable.

On behalf of an owner, performed a review of an EPC contractor’s project management performance and a schedule delay analysis to allocate responsibility for delays to the engineering, procurement, and construction of a multibillion-dollar nickel processing plant in Newfoundland, Canada.  The primary issue was standard of care and whether the EPC contractor was grossly negligent in its performance.  Prepared expert reports and testified in arbitration.

Provided schedule and damages analysis services and prepared a $1.2 million claim for a contractor that built a grocery store. Responsible for auditing and recoding invoices and timesheets, preparing a cost variance analysis and calculating damages, recreating the as-built schedule, and identifying and apportioning delays.