On behalf of a paint manufacturer, prepared an expert report refuting an EPC contractor’s claim for delay and disruption allegedly resulting from work associated with removal of lead-containing paint from the process plant modules and platforms of an offshore oil production facility installed in the Gulf of Mexico. Case settled prior to trial. The project also involved the defense against the owner’s delay claim for recovery of lost profits due to the delay to the achievement of first oil allegedly caused by the lead abatement program. Presented an expert report demonstrating that the project would have been delayed because of concurrent delay by the EPC contractor. Testified in deposition, which resulted in a successful settlement of the dispute.

On behalf of an owner, evaluated its position for a claim against the EPCM contractor for mismanagement, cost overruns, and delays on the performance of a cost reimbursable contract to design and build an offshore oil and gas production facility. Performed a schedule and cost variance analysis to identify where delays and cost overruns occurred and the allocated causes for such overruns against the owner and the contractor.

On behalf of an EPC contractor, analyzed a claim for delay during the design and construction of an offshore platform. Prepared an expert report in anticipation of arbitration. The case settled.

On behalf of a major U.S. oil company, evaluated potential delay claims from the contractor associated with a DCS and alarm management upgrade to an offshore platform in the North Sea.

On behalf of a Swedish subcontractor, reviewed its claim against an EPC contractor for delay and loss of productivity associated with the fabrication and assembly of living quarters for an offshore oil production facility.

On behalf of a major oil company, reviewed its ITB package for preparation of the FEED for the design of the topsides facilities for an offshore deep-sea oil and gas production platform. Recommended clauses to resolve potential inconsistencies, ambiguities, and conflicts. Prepared clauses for cost and schedule control procedures.