The project centered on disputes between a major contractor and a mechanical/electrical subcontractor on alleged delay and disruption impacts during the construction of a 380 MW power facility due to alleged late information, delayed procurement, and changes. Project completion was significantly delayed, and the subcontractor claimed the contractor caused the negative schedule impacts, subsequently submitting a request for an equitable adjustment (REA) and filing for arbitration. Team leader engaged to consult on the main contractor’s defense of the claim both during the contract execution works and the post completion arbitration events. This involved day-to-day contract administration, claims preparation, and overall management of claims team, outside counsel, and experts.

On behalf of a government controlled nuclear management company, performed a third-party review and upgrade analyses of its bidding processes and contract conditions for the decommissioning and new construction of nuclear power plants. Reviewed the contract/bidding documents and provided an independent risk management report covering best practices, PMBOK application, project success goals, and general procedures for upgrading contractor performance.

The project centered on the installation of a 230 kV transmission line: 24 miles underground and 3.5 miles overhead, through an extremely diverse and environmentally sensitive and challenged series of districts. The major infrastructure subcontractor alleged major delay and disruption impacts caused by the main contractor. Engaged to provide claim support services to the main contractor against the subcontractor’s claims. Prepared a defense position paper involving a CPM analysis, disruption analysis, and contract entitlement to rebut the subcontractor’s expert report, which ultimately resulted in mediation proceedings and a series of settlement negotiations. Also provided claims avoidance training and lessons learned reviews to the main contractor construction team to facilitate improved management of future similar projects.

The mechanical subcontractor executed a contract with a power contractor to complete outage work and repowering of CFB Unit #1. The power contractor caused project delays and interferences that delayed the required work to a period outside of the specified outage period and resulted in a shortage of manpower. The mechanical subcontractor accelerated work to maintain the work planned for the outage period. This required additional coordination of utilities and steam blows and functional tests of fuel system, oil-fired burners, CFB boiler, air ducts, flue gas system and stack, feed water systems, etc. Engaged to provide claims review services. Evaluated owner and contractor claims, including a review of the CPM schedule submittals. Produced a schedule delay and productivity analysis to determine responsibility for project delays. The claims team found that power contractor delays and interferences were primarily responsible for the acceleration effort and difficulties experienced by the mechanical subcontractor during the mechanical completion and operational testing phases of work.

On behalf of a piping manufacturer, analyzed the fabrication of piping components as an element of the fabrication and erection of HRSGs including the identification of aspects of the delay resulting from the actions of the various parties included in the project. Prepared an expert report, which led to settlement of the matter.

On behalf of a piping manufacturer, analyzed the fabrication of piping components as an element of the fabrication and erection of HRSGs including the identification of aspects of the delay resulting from the actions of the various parties included in the project. Prepared an expert report, which led to settlement of the matter.